还剩4页未读,继续阅读
文本内容:
2025工程管理与合同风险控制及合同索赔Contract No.:Date:Contracting Parties:Party A:Party B:Recitals:Party Aand Party B hereinafter referred to as thePartieshave agreedto collaborateon theProjecthereinafterreferred toas the Project.The Projectis subject to the laws andregulations of thePeoples Republicof China,including butnot limitedto the《Contract Lawof thePeoples Republicof China》and the《Regulations onQuality Managementof ConstructionProjects》.
1.Project Description:The Projectentails thee.g.,design,construction,and/or supervisionof thelocatedat.The projectscope includesandis expectedto becompleted byhereinafterreferred toas theCompletion Date.
2.Contract Amount:The totalcontract amountfor theProject ishereinafterreferred toas theContract Amount.Paymentterms andconditions aredetailed in Schedule A.第1页共6页
3.Risk Managementand Control:
3.1Risk Identification:The Partiesacknowledge thatthe executionof theProjectmay besubjecttorisks,including butnot limitedto:Changes inproject requirementsengineering changes;Delays causedby unforeseencircumstances;Variations inmaterial andlabor costs;Force majeureevents.
3.2Risk Mitigation:The Partiesshall jointlywork onrisk mitigationmeasures,including:Conducting regularrisk assessments;Establishing contingencyplans forpotential disruptions;Communicating promptlyand transparentlyregarding anyidentifiedrisks.
3.3Risk Allocation:Risk allocationshall beas follows:shall bearthe riskof.shall bearthe riskof.
4.Contract Executionand Management:
4.1Project Manager:Party shallappoint aProject ManagerhereinafterreferredtoasthePM tooversee theexecutionof theProject.The PMshall ensurecompliance withtheterms ofthis Contractand theProject requirements.第2页共6页
4.2Change Orders:Any changesto theProject scope,timeline,or budgetshall be submittedas aformal ChangeOrder.The ChangeOrdershall be in writingand signedby bothParties.
4.3Progress andMilestones:The Partiesshall reviewproject progressat regularintervalsas specifiedinSchedule B.
4.4Quality Standards:All worksexecuted under this Contract shall complywithapplicable laws,regulations,and industrystandards.TheParties shallconduct inspectionsand testsas perSchedule C.
5.Claim Management:
5.1Eligibility forClaims:Either Party may submita claimif:The other Party hasfailed tofulfill contractualobligations;There hasbeen a breach of contract;Additional costsor delayshave beenincurred duetocircumstances beyondthe controlof theclaiming Party.
5.2Submission ofClaims:Claims shall be submittedin writingwithindays of the eventgiving riseto theclaim.The claimshallinclude:Detailed descriptionoftheclaim;Supporting documentation;第3页共6页Proposed resolution.
5.3Claim Resolution:The Partiesshall attemptto resolveclaims throughmutualagreement.If resolutionis notreached withindaysof claimsubmission,either Partymay referthe mattertofor disputeresolution.
6.Liability forBreach ofContract:
6.1Liability forNon-Performance:In theevent ofabreachofcontract,the违约ing Partyshallcompensate theotherPartyfor alldirect andindirectlosses incurred.
6.2**remedies:**In additionto compensation,the innocentPartymayseekspecific performance,injunction,or otherlegal remedies.
7.Dispute Resolution:
7.1Negotiation:The Partiesagree tofirst attemptto resolvedisputesthrough goodfaith negotiations.
7.2Mediation:If negotiationsfail,either Partymay referthe disputetofor mediation.
7.3Arbitration:If mediationfails,the disputeshall bereferred toforbinding arbitrationin accordancewith theRules.第4页共6页
7.4Litigation:As alast resort,either Partymay initiatelegalproceedings inCourt.
8.Miscellaneous Provisions:
8.1Governing Law:This Contract shallbegoverned byand construedinaccordance withthelawsof.
8.2Entire Agreement:This Contractconstitutes theentire agreementbetweenthe Partiesand supersedesall prioragreements,representations,or understandings.
8.3Amendments:Any amendmentsto thisContractshallbe inwriting andsignedby bothParties.
8.4Notices:All noticesunderthisContractshallbeinwriting anddeliveredto theaddresses specifiedin thisContract.
8.5Counterparts:This Contractmay beexecuted incounterparts,each ofwhichshallbedeemed anoriginal andtogether constituteoneand thesame instrument.Schedule A-Payment TermsPaymentSchedule:.Payment Methods:.ScheduleB-Project Milestones第5页共6页Milestones:.Review Process:.Schedule C-Quality ControlInspectionProcess:.Testing Requirements:.In witnesswhereof,the Partieshereto haveentered intothisContract asofthedate firstwritten above.Party A:Name:Position:Signature:Date:PartyB:Name:Position:Signature:Date:第6页共6页。
个人认证
优秀文档
获得点赞 0